Terms and Conditions

Welcome to the Terms and Conditions webpage of Starlit Devs (“the Company”). These terms and conditions govern your use of our website and purchasing our services. By accessing our website and making a purchase, you agree to comply with these terms and conditions in their entirety. Please read them carefully before using our services.

1. Definitions and Interpretation

1.1. “Company” refers to Starlit Devs, the provider of services.

1.2. “Client” refers to “you” or “your”

1.3. “Website” refers to the official website of Starlit Devs, accessible at www.starlitdevs.com.

1.4. “Services” refers to the software development, consulting, and related services offered by the Company.

2. Legal Agreement: 

This agreement is a binding legal agreement between Client and StarlitDevs. The agreement constitutes the entire agreement between Client and StarlitDevs in relation to the Services. It does not include any terms and conditions of Client (including on any purchase order or other document submitted by Client) unless agreed to in writing by StarlitDevs.

3. Term of Agreement: 

This agreement commences on the start date of the project and will continue until the date of completion of the Services or Support Services (as applicable), unless terminated earlier in accordance with this agreement.

4. Services StarlitDevs will provide: 

StarlitDevs will:

  • Provide the Services;
  • Commence provision of the Services on the start date;
  • Use its best endeavours to ensure the Services are provided in compliance with all relevant Australian legislation;
  • Provide the Services with care and skill;
  • Provide support in respect of the Services
  • Act in Client’s best interests but will not do anything which is unethical or unlawful;
  • Not provide any legal, financial or taxation advice;
  • Provide only the resources as required to be provided by StarlitDevs to deliver the Services;
  • Mot be deemed to be in control of Client’s site or project at any time and shall have no responsibility for occupational health and safety (which is the responsibility of Client);
  • Provide the Services to Client alone and will not regard any other entity as its client in relation to the Services; and
  • Shall determine at its discretion the personnel who will provide the Services.

4.1 Additional Services: 

At the request of Client, StarlitDevs may provide work and services additional to the Services including (a) any additional services; and (b) updates required as a result of changes to any relevant internet interface or services required in respect of matters set out in clause 5 (Additional Services). Client agrees and acknowledges that:

  • the provision of any Additional Services by StarlitDevs is subject always to this agreement and Additional Services are within Services for the purposes of this agreement;
  • the fee for any Additional Services is not included within the fee for the Services and will be charged at StarlitDevs’s time based charge out rates, and
  • by submitting a quick quote or other form of purchase order to StarlitDevs in respect of any Additional Services, Client agrees to pay for the Additional Services.

4.2 Limitations on Services: 

Client agrees and acknowledges that:

  • StarlitDevs will not provide the following services under this agreement (StarlitDevs may at its discretion provide these services as Additional Services at the request of Client):
    • (i) support outside Business Hours. In this agreement, Business Hours means 9am to 5pm Perth time on any day except a Saturday, Sunday or public holiday in Western Australia;
    • (ii) support of or assisting the client in the use of operating systems, ancillary services or software or other platforms;
    • (iii) managing authorised usernames and passwords;
    • (iv) installing or managing Client’s security measures;
    • (v) support where Service impairment results from installation, uninstallation, or use of other software applications;
    • (vi) recovery of damage or data loss arising from hard drive or CPU failure, network failure, misuse, negligence, alteration, improper wiring, malware, viruses or failure to complete daily and weekly backups;
    • (vii) support where Client has failed to implement a recommendation from StarlitDevs where in the reasonable opinion of StarlitDevs the recommendation should be implemented to ensure StarlitDevs can properly deliver the Services; or
    • (viii) consulting services or accelerated development or advanced customisations of or enhancements to or new features of the Services.

5. Client Authority, Exclusivity and Warranties:

Client authorises StarlitDevs to:

  • (i) conduct all activities as may be required to perform the Services, including submitting websites to search engines and any other resources or relevant sites;
  • (ii) modify any of Client’s websites, including modifying the metadata of any website, for the purposes of providing the Services;
  • (iii) use relevant materials, facilities, keywords and phrases, including intellectual property belonging to Client, for the purpose of delivering the Services.
  • During the term of this agreement, Client shall not permit any website developer or search engine optimisation provider to:
    • (i) perform or deliver any service which is within the Services; or
    • (ii) have access to any of Client’s websites.
  • Client agrees that StarlitDevs will not be responsible for any of Client’s websites or search engine rankings if Client does not comply with clause 6(b).
  • Subject to clause 6(b), if Client is required to give access to Client’s website to any third party Client must give prior notice to StarlitDevs.

6. Client’s Responsibilities: 

In order to ensure that StarlitDevs is able to properly deliver the Services, Client:

  • must ensure that its computers and communication systems are suitably configured, maintained, and operated so as to enable StarlitDevs to deliver the Services;
  • must cooperate with StarlitDevs in:
    • (i) performing diagnostic procedures and communicating information in order to facilitate support provided by StarlitDevs;
    • (ii) testing its websites to determine whether a given problem has been solved; and
    • (iii) implementing workarounds intended to reduce the criticality of a given problem;
  • must not install or use software that may, in the reasonable opinion of StarlitDevs, impair the proper delivery of the Services by StarlitDevs;
  • warrants to StarlitDevs that Client’s websites are not hosted by free web hosting providers; and
  • agrees that if StarlitDevs:
    • (i) Reasonably determines that Client’s web hosting provider may be part of a ‘bad neighbourhood’; or
    • (ii) Considers that for optimisation of the Services, Client should change its’ web hosting provider,
  • then Client will, at StarlitDevs’s request, change its web hosting provider.

7. Delivery of Client Materials:

  • Client must provide StarlitDevs with copies of all logos, graphics, software, data and other materials and information which Client wishes StarlitDevs to incorporate into the website (Client Materials).
  • Client warrants that all Client Materials that it or anyone on its behalf supplies to StarlitDevs, and all use thereof by StarlitDevs for the purposes of this agreement, will not infringe the rights of any person or breach any law or regulation.
  • Client indemnifies StarlitDevs in respect of all loss suffered or incurred by StarlitDevs as a result of a breach of the warranty in clause 9(b) or in respect of any use of Client Materials supplied by or on behalf of Client to StarlitDevs.

Nominated contact person: 

StarlitDevs will deal directly with Client’s nominated contact person and will not take instructions or technical feedback from any other person.

8. Development Specifications:

  • The Services to be provided to Client and the elements of the website will comply with the development specifications.
  • If Client notifies StarlitDevs that it requires changes to the scope, nature or any elements of the development specifications, including elements of the website design, after the start date, then:
    • (i) StarlitDevs will provide written notice to the Client with details of the additional time, materials, resources and fees required to undertake the changes to the development specifications; and
    • (ii) if Client agrees to the additional time, materials and resources to be provided and the additional fees required to undertake the changes to the development specifications,
  • this agreement will be considered varied to include such changes as set out in the notice provided by StarlitDevs in paragraph (i) above.
  • StarlitDevs will use best endeavours to ensure that the website is responsive and performs to the development specifications on all devices, however StarlitDevs cannot guarantee device and browser compatibility as this is outside of StarlitDevs’s control.

Development Stages:

  • StarlitDevs will use reasonable endeavours to complete each development stage within the timeframes specified.
  • Client acknowledges that there may be delays in completing any development stage and StarlitDevs will, upon becoming aware of a delay, notify Client as soon as reasonably practicable in writing of the cause of the delay and estimated date of completion.
  • Client agrees that StarlitDevs will not be responsible for any delays in completing any development stage where that delay is caused by any act or omission of Client or any other matter beyond the reasonable control of StarlitDevs.
  • If StarlitDevs requests information from Client and Client does not respond to such request within 5 Business Days, StarlitDevs may halt the Services until a response is received, at such time new timeframes for the remaining development stages will be determined and communicated to Client. The amended timeframes for the remaining development stages will not affect payment dates of any fees payable.

Design Stage:

  • During any design stage, Client will be provided with a maximum of two design concepts. Additional design concepts will not be provided.
  • Each design stage of the website design may be revised by Client instruction a maximum of twice. Any additional revisions will be charged at StarlitDevss hourly rate from time to time.
  • Once a webpage design has been approved by Client, the design concept and overall style of the page will be locked and additional changes cannot be made until after the website launch date, and will be charged at StarlitDevss hourly rate from time to time.
  • Design aspects such as branding, imagery and other visual content provided by Client must be owned by Client, and be of a quality deemed satisfactory for website publication at the sole discration of StarlitDevs.

Content Stage:

  • Client must be responsive, available and willing to collaborate with StarlitDevs during the content stage of the website.
  • If Client does not respond to StarlitDevs correspondence within 48 hours of receipt during the content stage, StarlitDevs may at its discretion create and use content that it reasonably deems to be appropriate for the website for the purposes of progressing to the development stage, and the created content can be changed as a part of paid support after the website launch date.
  • StarlitDevs will provide an initial draft of the content to Client for review and approval.
  • StarlitDevs will revise content in accordance with feedback of Client on one occasion only. Additional revisions can be made as a part of paid support after the website launch date.
  • StarlitDevs must receive final content approval from Client before the development stage. If Client does not provide StarlitDevs with final content approval, then the content will be added to the website in its non-approved form for the purposes of progressing to the development stage, and the created content can be changed as a part of paid support after the website launch date.

Acceptance Testing Stage:

  • StarlitDevs must test the website to evaluate whether the website meets the development specifications as soon as practicable after completion of installation of the website.
  • Upon completion of the Acceptance Tests, StarlitDevs will provide Client with certification that the website operates in accordance with and otherwise complies with the development specifications.
  • If Client, acting reasonably, determines that the website does not meet the development specifications in all material respects, Client must within 7 days of receipt of certification from StarlitDevs in accordance with clause 12(b), provide notice to StarlitDevs setting out in detail a description of which of the Acceptance Tests have failed (Failure Notice).
  • StarlitDevs must, within 30 days of receipt of a Failure Notice, modify the website so it meets the development specifications in all material respects and deliver the modified version to Client.
  • If Client, acting reasonably, determines that the revised website does not meet the development specifications, Client may terminate this agreement by notice in writing to StarlitDevs. Client must pay StarlitDevs for all Services performed up to the date of termination.

Website Launch Stage:

  • StarlitDevs will publish the website live upon completion of the Acceptance Testing Stage.
  • All content and design changes to the website after the date that the website is live are charged as a part of paid support at StarlitDevs’s hourly rate from time to time, unless covered within the warranty period pursuant to clause 16 or a maintenance package.
  • Whilst StarlitDevs uses best endeavours to ensure the website performs and ranks well within search engines, StarlitDevs cannot guarantee increased business and website traffic after the website is launched, nor is StarlitDevs liable for any loss of business or website traffic after the website is launched.
  • StarlitDevs is not responsible for ensuring that the website complies with privacy, data storage, foreign visitor, cookies or other legal obligations under any applicable law or industry code within Australia or internationally.

Warranty Period:

  • A warranty period of one month applies to the website commencing on the website launch date (“Warranty Period”).
  • During the Warranty Period, StarlitDevs will:
    • (i) fix any technical glitch or bug with the website; and
    • (ii) fix any issues with website speed, functionality, broken links and pages, responsiveness, or plug ins.
  • The Warranty Period does not cover:
    • (i) changes to cosmetic, design, photo or text content of the website; or
    • (ii) webhosting or security issues.

Maintenance:

  • StarlitDevs will provide maintenance services as part of the Services to Client following delivery of the Website to the Client.
  • If Client wishes to obtain any additional maintenance services outside of what is set it must request these from StarlitDevs and, if StarlitDevs agrees to provide such Additional Maintenance Services, StarlitDevs will charge for such Additional Maintenance Services at StarlitDevs’s time based charge out rates.

Support Provided:

  • StarlitDevs shall use commercially reasonable efforts to provide support (“Support Services”) but does not guarantee that any defects in the Client’s websites or Services will be fixed by StarlitDevs.
  • Client acknowledges that StarlitDevs relies on third party interfaces and databases to deliver the Services and as a result StarlitDevs cannot guarantee uninterrupted access to and use of those third party internet interfaces and databases at all times.

Fees: 

Except as otherwise agreed in writing with StarlitDevs;

  • the fee for the Services will be as specified
  • where hourly rates are specified, StarlitDevs will record time spent on the Services in 30 minute blocks. Time spent for shorter periods of time is rounded up to the nearest 30 minute block;
  • any fee estimate or quote provided by StarlitDevs will not limit the fees that StarlitDevs may charge unless StarlitDevs has agreed that a fixed fee will be charged; and
  • StarlitDevs reserves the right to adjust its time based charge out rates on each 1 January and 1 July by an amount not less than the change in the Consumer Price Index (All Groups) Perth in the preceding six months.
  • StarlitDevs reserves the right to change fixed price or recurring monthly charges at any time at StarlitDevs’s discretion. These price changes will only affect Services delivered after the date of the price change, and will not alter any recurring charged services in place at the time of the price change as agreed between StarlitDevs and Client.

Disbursements:

  • Client agrees that external disbursements are not included in StarlitDevs’s fees. Client agrees to reimburse reasonable business expenses incurred by StarlitDevs in the performance of the Services. StarlitDevs will use its best endeavours to seek authorisation from Client prior to incurring such expenses.
  • StarlitDevs agrees to provide Client with tax invoices for all expenses StarlitDevs seeks to have reimbursed.

Tax invoices:

  • Tax invoices:
    • (i) will be issued by StarlitDevs and must be paid on the terms as specified in the invoice;
    • (ii) shall be deemed correct unless disputed in writing within 7 days of the date of the invoice; and
    • (iii) must be paid in full notwithstanding any counterclaim or set-off Client may claim against StarlitDevs.
  • StarlitDevs reserves the right to charge interest at 12% per annum, calculated daily, on tax invoices that are not paid in full and on time.

Insurances: 

Client agrees to procure and maintain at its expense appropriate injury, death and property loss insurance covering StarlitDevs’s personnel while at Client’s site.

Confidentiality: 

StarlitDevs and Client each agree:

  • not to disclose or use for an improper purpose any Confidential Information received or obtained from the other party; and
  • that each party can disclose Confidential Information received by it if, and to the extent,:
    • (i) required by law or required by a Court, stock exchange or regulatory or governmental body; or
    • (ii) the information is disclosed on a confidential basis to professional advisers or bankers; or
    • (iii) the information is disclosed to a director, officer, employee or agent of the party whose function requires them to have the information; or
    • (iv) the information is in the public domain otherwise than through the fault of the disclosing party; or
    • (v) the other party has agreed to the disclosure in writing,
  • provided a party intending to disclose information under any of paragraphs (i)–(iii) above consults with the other party first. If a party makes any disclosure under any paragraphs (i) and (ii) above it must inform the other party as soon as possible;
  • “Confidential Information” means all trade secrets, know-how, financial, marketing, management, technical and other information which is confidential or of a sensitive nature, including information regarding business strategy and processes, but excludes information in the public domain.
  • Client agrees that the identity of Client is not Confidential Information and that StarlitDevs may disclose to third parties that StarlitDevs has been engaged by Client.

Intellectual Property:

  • The parties agree that:
    • (i) each party’s Background IP remains vested in that party; and
    • (ii) any Intellectual Property created as a result of this agreement vests in Client on creation.
  • StarlitDevs hereby grants to Client a non-exclusive, perpetual, royalty-free, irrevocable, sub-licensable and transferable right to use its Background IP to the extent it is incorporated into the website.
  • “Intellectual Property” means all forms of intellectual and industrial property whether registered or unregistered, including copyright, trade marks, designs, trade secrets, know-how, inventions and patents.
  • “Background IP” means any Intellectual Property of a party which is in existence prior to the date of this agreement or which comes into existence after the date of this agreement other than in connection with the Services.

Liability and Indemnity: 

Client agrees that except to the extent caused by a breach of this agreement by StarlitDevs or the negligence or wilful misconduct by StarlitDevs or its officers, employees or contractors, StarlitDevs and its officers, employees and contractors shall, to the maximum extent permitted by law, not be liable to Client or its officers and employees or contractors or any other entity for any Claims whatsoever:

  • in relation to provision or non-provision of the Services or arising from any act or omission by StarlitDevs relating to the Services;
  • arising from any act or omission of any third party, including the unavailability or performance of any search engine, relevant internet interface or database or the listing or ranking of any Client’s website;
  • in relation to the matters set out in clause 5;
  • in relation to the use by Client (or its officers, employees, agents or contractors) of any Documents;
  • in the event that any transaction contemplated by Client does not proceed; or
  • in relation to acts or omissions of Client or any third party,

 

and Client shall and hereby does indemnify and hold StarlitDevs and its officers, employees and contractors harmless from all such Claims. In this agreement “Claim” means any claim, expense, demand, action, suit, proceeding, loss or damage of any kind or character (including without limitation for legal costs or special, indirect, punitive or consequential damages, loss of profit or business opportunity or payment of liquidated sums).

 

Warranties:

  • Subject to clause 26(a) and to the maximum extent permitted by law the Services are provided without any warranties of any kind, either express or implied, including warranties of title, non-infringement of fitness for any purpose, accuracy, completeness or currentness. Any warranty which is implied by law or statute is excluded to the maximum extent permitted.
  • Nothing in this Agreement may be read or applied so as to purport to exclude, restrict or modify or have the effect of excluding, restricting or modifying the application in relation to the supply of any Services pursuant to this agreement of all or any of the provisions of the Competition and Consumer Act 2010 or any relevant State or Federal law. The Australian Consumer Law Schedule of the Competition and Consumer Act 2010 provides consumer rights and remedies that may not be contracted out of, in part or wholly. Where those consumer rights and remedies apply to the supply of the Services by StarlitDevs to Client and cannot be contracted out of, they apply and override any inconsistent provisions in this agreement but only to the extent of the inconsistency.

Non solicitation: 

Client agrees:

  • not to, directly or indirectly, employ, solicit, engage or direct for purposes of employment or contracting services any of StarlitDevs’s staff or contractors during the term of this agreement and for a period of 12 months thereafter;
  • that if it does not comply with paragraph (a) above, it will pay to StarlitDevs on demand a placement fee of:
    • (i) in the case of a StarlitDevs employee, 100% of the employee’s total annual remuneration package from StarlitDevs (including superannuation); or
    • (ii) in the case of a StarlitDevs contractor, 100% of the average of the following two amounts (A) the total payments made to or in respect of the contractor over the previous 12 months by StarlitDevs, and (B) the expected total payments to be made to or in respect of the contractor over the subsequent 12 months by StarlitDevs if the contractor had continued to work with StarlitDevs for those 12 months, in both cases as certified by StarlitDevs’s accountant and including all fees and oncosts; and
  • that those amounts are a fair measure of the loss that StarlitDevs will suffer if Client does not comply with this clause.

Delay/Force majeure: 

StarlitDevs and Client will each not be respectively liable for any delay or failure in the performance of obligations that arise out of causes beyond their control, including but not limited to electrical outages, internet, communications or computer failures, acts of god, fires, floods, epidemics, riots, strikes, embargoes, earthquakes, severe weather, war, governmental action, and acts or omissions of subcontractors or third parties.

Suspension, Expiry and Termination:

  • StarlitDevs may suspend the delivery of the Services during any period in which an amount owing by Client pursuant to this agreement is overdue.
  • If either party is in breach of this agreement then the party alleging the breach may serve a default notice on the other party setting out the full particulars of the alleged breach and the acts required to rectify the breach. A party may terminate this agreement if:
    • (i) it has issued a notice of default and the default alleged therein remains unrectified 14 days after service of the default notice; or
    • (ii) to the extent permitted by law, the other party goes into liquidation, has a receiver or manager or administrator appointed, is declared bankrupt or becomes subject to Part X of the Bankruptcy Act 1966.

GST: 

All fees referred to in this agreement do not include goods and services tax (GST) unless expressly stated otherwise. Client must pay to StarlitDevs, on each date Client must make payment for a taxable supply under this agreement, an additional amount equal to the GST payable on the GST free amount of the taxable supply. In this agreement “GST, “supply”, “taxable supply” and “tax invoice” have the same meaning as in A New Tax System (Goods and Services Tax) Act 1999.

Other:

  • Reference in this agreement to the singular includes the plural, and to any party to this agreement includes the party and its successor, administrator, personal representative, transferees and assigns.
  • A notice to be served under this agreement will be duly served if it is in writing and is sent to the address for each party by certified mail, facsimile, personal delivery or email, provided there is proof of delivery.
  • Neither party may assign or transfer any right or obligation under this agreement without the written consent of the other.
  • Nothing in this agreement constitutes or creates a relationship of partnership, employment, agency or joint venture between StarlitDevs and Client.
  • If any provision or part provision of this agreement is invalid, unenforceable or illegal then it shall be deemed deleted and the remaining parts shall continue to apply with full force and effect.
  • This agreement is governed by the law in force in Western Australia. Each party irrevocably submits to the jurisdiction of the courts of Western Australia with respect to any Claim which may be brought at any time relating in any way to this Agreement.
  • This agreement may only be varied in writing signed by both Parties.
  • Any omission by a party to enforce any provision of this agreement shall not operate as a waiver and will not prejudice the rights of the party to enforce any of the provisions.
  • All provisions in this agreement in respect of indemnities, IP ownership, confidentiality and non-solicitation survive the termination of this agreement. This agreement may be exchanged by execution in counterparts and the exchange of executed facsimile or PDF copies shall constitute a binding and complete agreement.
Scroll to Top